KR101805453B1 - A method of handling information in preparation against claims and a system therefor - Google Patents

Abstract

A method of handling information in preparation for claims according to the present invention comprises a step of establishing a claim management plan; a step of identifying and monitoring a claim; a step of determining whether a claim event is generated; a step of creating a claim letter; a step of creating a claim package; a step of recording and managing the claim. Accordingly, claim management through management of a construction project such as process and cost can be performed. The integrated management of data generated during a project can be possible when using PMIS to share information among business participants.

Description

[0001] The present invention relates to a method for handling claim-cost information and a system therefor,

The present invention relates to a method of processing claim cost information and a system therefor, and more particularly, to a method and a system for processing claim cost information, and more particularly, Claims: What is claimed is: 1. A method for processing a claim, comprising the steps of: collecting data with comparable input data and managing the claim to be filed or a claim to be filed;

Over the past decade, domestic builders' overseas construction market orders have been increasing steadily. Domestic construction companies have maintained steady growth in the overseas construction market, but the profitability of the business itself has been declining due to claims made by domestic construction companies in the overseas construction market.

The average percentage of claims filed against the total contract value of overseas construction is about 2 ~ 5%, of which more than 10% is frequent and in serious cases it is close to 50% of the contract amount .

According to related research, the average return of overseas construction projects in Korea is 3 ~ 7% on average, and the average return of domestic construction companies is 4 And 5%, respectively), it can be understood that the claim size of 2 ~ 5% on average is directly related to the profitability of the business.

Therefore, the profitability of the overseas construction business is deteriorating despite the active entry of domestic construction companies into the overseas construction market. Compared with the advanced foreign construction companies whose construction contract management is thorough, Korea's construction related practitioners generally organize institutional responsibility and authority In addition, it is because of insufficient experience and lack of ability to manage claims and coping ability. In order to secure profitability of construction business, it is necessary to strengthen overall business management capacity including claims and dispute management.

The project management information system (PMIS) related to domestic and foreign studies has been conducted on computerization of construction project management and integration of project management data. In order to upgrade the construction industry, it is necessary to conduct systematic work according to the procedure and to provide objective data And to accumulate and utilize them.

An example of the prior art related to this is Korean Patent No. 10-1167850. This is a method and system for processing construction cost information for each part of detailed space. It draws out the limitations of cost accounting method and the problem of construction cost statement for each type expressing existing construction cost, and at the same time, It is to improve.

However, such conventional technology has been developed in order to prevent claims and disputes, and it is not a technology that can actually be used for claims and disputes, and thus can not easily deal with claims and disputes. In other words, according to this, the main factors of claim generation can not be prepared for business management including claims and dispute management, and it can not be used as a method to reduce business mistakes and immaturity and to produce claim proof data.

Therefore, there is a need for an information processing method and system that can easily cope with a claim, but it is hard to find yet. More specifically, it is possible to carry out the construction business management to prepare for the claims that may arise in the construction business, to perform the work according to the business procedure document suitable for the construction business, and to create the proof data in the case of the claim It is necessary to construct a PMIS that can be used in construction projects.

KR 10-1167850 B1

The present invention for solving the above-mentioned problems of the prior art is to provide a way for a Korean construction company to perform a construction project management from the viewpoint of a contractor when performing an overseas construction project (providing a business process) It is an object of the present invention to provide a system for easily collecting data with input data and managing a claim that can be filed or a claim to be filed.

According to an aspect of the present invention, there is provided a method of processing claim cost information, comprising: establishing a claim management plan; Identifying and identifying claims; Determining whether a claim event has occurred; Creating a claim letter; Creating a claims package; And recording and managing the claims.

Further, the step of establishing the claim management plan may include: defining a claim-related term; Classifying the type of claim based on the cause of the claim; Establishing claims process; And establishing a countermeasure for claims.

The step of identifying and monitoring the claim may further include: creating a customer return checklist form; Creating a contractor checklist form; Completing the other return checklist form; And completing or collecting the claim management check list.

Also, it is preferable that the claim event includes matters that occur in the monthly meeting, the progress report meeting, or in the event that the plan for the process is compared with the actual value.

In addition, the step of creating the claim letter may include: checking a claim event; Sending a claim notification letter; Submitting detailed proofs; And an approval judgment step.

The step of generating the claim package may include: organizing a project outline; Reviewing an initial baseline; Organizing a claim event list; Selecting a claim event; Rearranging the claim event history; Creating a repetitive activity group (Fragnet); Selecting a delay analysis method (TIA); Reviewing progress and delay analysis of progress; And creating a claim document.

The recording and managing of the claim may include: creating a claim record list target; Recording or archiving a claim history; Managing the action history; And creating a status report.

According to an aspect of the present invention, there is provided a claim-cost information processing system including a claims management plan collection module; Claim identification monitoring module; Claim Letter Creation Module; A claim package generation module; And a claim record management module.

In addition, the claim management plan collection module preferably has a function of defining a claim-related term, determining a claim type, establishing a claim promotion procedure, and establishing a countermeasure for claims.

In addition, the claim identification monitoring module preferably has a function of storing, supplementing or collecting the created orderer, contractor, and other checklist form, and determining whether a claim event has occurred.

In addition, the claim letter writing module is preferably configured to check a claim event, to voice a claim notification letter, to submit detailed proof contents, and to determine whether or not to approve the claim.

In addition, the claim package creation module can organize the project outline, review the initial baseline, organize the claim event list, select the claim event, rearrange the claim event history, create the repeat activity group, It is desirable to be configured to select a method, review progress and delay analysis, and create a claim document.

The claim record management module is preferably configured to create a claim record list object, record or archive a claim record, manage a record of the action, and generate a status report.

The details of other embodiments are included in the detailed description and the accompanying drawings.

BRIEF DESCRIPTION OF THE DRAWINGS The advantages and / or features of the present invention and the manner of achieving them will be apparent from and elucidated with reference to the embodiments described hereinafter in conjunction with the accompanying drawings. It should be understood, however, that the invention is not limited to the disclosed embodiments, but may be embodied in many different forms and should not be construed as being limited to the embodiments set forth herein. Rather, these embodiments are provided so that this disclosure will be thorough and complete, and will fully convey the scope of the invention to those skilled in the art. And is provided to fully explain the scope of the present invention to those skilled in the art.

As described above, according to the method of claim cost information processing and the system therefor according to the present invention, claims management is performed through management of construction projects such as process and cost, and when a PMIS is utilized Integrated management of data generated during the process is possible.

In addition, according to this system, claims can be easily prepared even in a field where there is no specialist who continuously monitors and monitors during the life cycle of the project, and since the information of the task is registered and managed in the computer, The omission can be prevented in advance.

In addition, the initial plan data on the construction management items such as the process and cost when performing the construction project management using the constructed PMIS, and the data that occurred while the construction project was carried out were used for objective data supporting the situation As shown in FIG.

FIG. 1 is a flowchart illustrating an overall configuration of a method of processing a claim versus cost information according to a preferred embodiment of the present invention.
FIG. 2 is a flowchart for describing a step of establishing a management plan of claims in a claim-cost information processing method according to a preferred embodiment of the present invention.
FIG. 3 is a flowchart for explaining a step of identifying and monitoring a claim in a claim versus cost information processing method according to a preferred embodiment of the present invention.
FIG. 4 is a flowchart for describing in detail a step of creating a claim letter in a claim versus cost information processing method according to a preferred embodiment of the present invention.
FIG. 5 is a flowchart for describing in detail a step of preparing a claim package in the method of processing a claim versus cost information according to a preferred embodiment of the present invention.
FIG. 6 is a flowchart illustrating in detail a step of managing a claim history in a claim-cost information processing method according to a preferred embodiment of the present invention.
FIG. 7 is a schematic diagram showing a main configuration of a claim-cost information processing system according to a preferred embodiment of the present invention.

Before describing the present invention in detail, terms and words used herein should not be construed as being unconditionally limited in a conventional or dictionary sense, and the inventor of the present invention should not be interpreted in the best way It is to be understood that the concepts of various terms can be properly defined and used, and further, these terms and words should be interpreted in terms of meaning and concept consistent with the technical idea of the present invention.

That is, the terms used herein are used only to describe preferred embodiments of the present invention, and are not intended to specifically limit the contents of the present invention, It should be noted that this is a defined term.

Also, in this specification, the singular forms "a", "an", and "the" include plural referents unless the context clearly dictates otherwise, and it should be understood that they may include singular do.

Where an element is referred to as "comprising" another element throughout this specification, the term " comprises " does not exclude any other element, It can mean that you can do it.

Further, when it is stated that an element is "inside or connected to" another element, the element may be directly connected to or in contact with the other element, A third component or means for fixing or connecting the component to another component may be present when the component is spaced apart from the first component by a predetermined distance, It should be noted that the description of the components or means of 3 may be omitted.

On the other hand, it should be understood that there is no third component or means when an element is described as being "directly connected" or "directly connected" to another element.

Likewise, other expressions that describe the relationship between the components, such as "between" and "immediately", or "neighboring to" and "directly adjacent to" .

In this specification, terms such as "one side", "other side", "one side", "other side", "first", "second" Is used to clearly distinguish one element from another element, and it should be understood that the meaning of the element is not limited by such term.

It is also to be understood that terms related to positions such as "top", "bottom", "left", "right" in this specification are used to indicate relative positions in the drawing, Unless an absolute position is specified for these positions, it should not be understood that these position-related terms refer to absolute positions.

Furthermore, in the specification of the present invention, the terms "part", "unit", "module", "device" and the like mean a unit capable of handling one or more functions or operations, Or software, or a combination of hardware and software.

In this specification, the same reference numerals are used for the respective components of the drawings to denote the same reference numerals even though they are shown in different drawings, that is, the same reference numerals throughout the specification The symbols indicate the same components.

In the drawings attached to the present specification, the size, position, coupling relationship, and the like of each constituent element of the present invention may be partially or exaggerated or omitted or omitted for the sake of clarity of description of the present invention or for convenience of explanation May be described, and therefore the proportion or scale may not be rigorous.

Further, in the following description of the present invention, a detailed description of a configuration that is considered to be unnecessarily blurring the gist of the present invention, for example, a known technology including the prior art may be omitted.

Hereinafter, a method of processing claim cost information according to an embodiment of the present invention and a system therefor will be described.

First, with reference to FIG. 1, a description will be given of an overall configuration of a method of processing a claim versus cost information according to a preferred embodiment of the present invention. FIG. 1 is a flowchart illustrating an overall configuration of a method of processing a claim versus cost information according to a preferred embodiment of the present invention.

The claim-cost information processing method according to a preferred embodiment of the present invention includes a step of establishing a claim management plan (S100), a step of identifying and monitoring a claim (S200), a step of determining whether a claim event is generated (S300) A step of creating a letter (S400), a step of creating a claim package (S500), and a step of recording and managing a claim (S600).

First, a step of establishing a claim management plan (S100) is a step of creating a plan for claims, risks, costs, process management, and the like, and a construction project is performed according to such a plan.

[0040] The step S100 of establishing a claim management plan according to an embodiment of the present invention will be described in further detail with reference to FIG. FIG. 2 is a flowchart for describing a step of establishing a management plan of claims in a claim-cost information processing method according to a preferred embodiment of the present invention.

In order for the claims management plan to be established, a claim-related term, for example, terms commonly used in process management or contract terms, is clearly defined in the claim-related term definition step S10.

After the claim-related terms are clearly defined, the type is classified on the basis of the cause of the claim in the step of identifying the claim type (S20). Here, the claim type can be variously classified according to the claim object, the state contract rule, the cause of the claim, and the basis of the claim, but the present invention classifies the type of the claim based on the cause of the claim.

In the preferred embodiment of the present invention, the types of claims according to the cause of the claim include: 1) claims regarding differences in site conditions, 2) claims relating to contract documents, 3) claims regarding construction changes, and 4) Claims related to loss of labor productivity, 6) Claim for air delay, 7) Claim for cancellation of contract, 8) Claim due to improper conduct of client or supervisor, 9) Construction environment claim, and 10) Claims are classified into 10 kinds in total.

In this step of identifying the claim type (S20), various types of claims are classified and preferably classified into 10 types as described above. Accordingly, it is possible to examine and analyze the frequency of occurrence of claims by type among a predetermined period including a time when a claim type is grasped.

For example, in the step of identifying the claim type (S20), the intervention cases of the Korean Commercial Arbitration Board and the Public Procurement Service between January 2005 and December 2009 are examined based on the above-mentioned 10 classified types, As a result, the results shown in Table 1 below can be obtained.

In addition, in the analysis result, the number of incidents and the frequency of incidents according to claim types, 3) claims for construction change, 6) claims for air delays, and 7) Respectively. The main drivers of these claim types were identified as shown in Table 2 below.

As a result, it is possible to analyze the main causes of the occurrence of claims, which are required to actively respond to construction projects.

In other words, if the type of claim is identified, in the step of establishing the claim promotion procedure (S30), it is possible to determine the part of the construction project management side that needs to be positively responded through the analysis of the main matter, have.

For example, referring to Table 1 and Table 2 above, when a domestic construction company conducts a construction project in an overseas construction market, 3) the frequency of claim types related to a construction change is ranked first, For example, change by order of owner, lack of design / specification, or error, and instruction to change work method or order.

Accordingly, the step of establishing the claim promotion procedure (S30) is a step of establishing a procedure including steps of securing the evidence data and making the claim document before and after the claim date, and managing the main factors sorted by the type of claim Can be established so that it can be done thoroughly.

In the step S40 of establishing the countermeasure for countermeasures, countermeasures are established so that the claimed claim can be compensated for, for example, the amount claimed for the claim, so as to achieve the object.

It is preferable that the step (S40) of establishing a countermeasure for claim to achieve the purpose is to construct a PMIS based on the construction project management system and the claim promotion procedure.

In the step of establishing countermeasures for such claims (S40), countermeasures designed to prevent errors in business, provide contractor's claim document form, secure sufficient evidence, and prepare for claims can be established have. According to this, a work practitioner can confirm their work contents and procedures, and the information of the work is registered and managed in a computerized manner, so that data omission due to mistakes and inexperiences in work can be prevented in advance.

The initial planning data for the construction management items such as process and cost, and the data that occurred during the construction project when constructing PMIS were used to manage the construction project, the objective data supporting the situation .

The claim management plan establishment step S100 may be performed based on the respective steps S10 to S40, in which a plan for claims, risk, cost, process management, and the like is established. That is, the optimized claim management plan can be established by defining the claims related terms (S10), identifying the types of claims (S20), establishing a claim promotion procedure (S30), and establishing a countermeasure for claims (S40) .

Next, referring to FIG. 3, step S200 of identifying and monitoring claims after step S100 of establishing a claim management plan according to a preferred embodiment of the present invention will be described in detail. FIG. 3 is a flowchart for explaining a step of identifying and monitoring a claim in a claim versus cost information processing method according to a preferred embodiment of the present invention.

In the step of identifying and monitoring the claim (S200), a check list necessary for identifying an event is generated, and the presence or absence of a claim event is confirmed while the generated check list is confirmed. Here, it is desirable that the event refers to an event related to a claim that is different from the plan in the construction project.

Step S200 of identifying and monitoring the claim includes steps S210, S220, and S230 of creating an order return checklist form (S210), creating a contractor receipt checklist form (S220) And supplementing / collecting the claim management check list (S240).

In the steps S210 and S220 of creating the checklist form of the ordering party and the contractor, the role, authority and responsibilities are defined for each performer, so that it is possible to quickly distinguish the responsibility when an event occurs. In the step S230 of creating the other return checklist form, a return checklist form is created in the case of not belonging to the contractor nor the contractor.

The checklist should preferably be a list containing the various claims type claims. Claims checklists are created and supplemented / collected (S240), and when a claim related event occurs (S300), the claim can be identified based on the checklist.

For example, if a claim-related event occurs and the claim is identified as a claim on air delay, then the major causes are the respective owner (contractor) liability, contractor (contractor) liability, and Other responsibilities (designer and third party).

In this case, claim-related events can occur when the contractor's staff, like the monthly meeting, mentions the need for a claim during a meeting. It is desirable that the event be made at the monthly meeting, at the progress report meeting, or when the actual value of the process is entered into the schedule, all of the abnormalities should be included.

It is preferable that the above-mentioned contents of the claim are specified on the basis of the countermeasures established in the step S40 of establishing the propulsion procedure and the countermeasures prepared in the step S30 for establishing the claim propulsion procedure.

In particular, the checklist items shown in Table 3 are the main cause of the air delay, and it is possible to quickly and accurately derive the proof of the claim through the quantification of the air delay object, so that it can cope with the air delay claim event strongly.

As shown in Table 4 below, four methods are used to quantify the air delay object. The US Court and UK Society Construction Law (SCL) have the highest rate of adopting TIA (Time Impact Analysis) It is desirable to develop an air delay algorithm based on this analysis method because it uses the TIA analysis methodology which has the highest objectivity of proof of the influence of delays and days of responsibility.

The present invention is based on the contractor's view that the output of the engineering procurement construction (EPC) business, which is executed based on the data linked with the process and the cost, ) ≪ / RTI > to generate air delay claims proof data.

The present invention quantifies each type of claim, such as a claim on construction change, a claim on contract document, etc., as well as a claim on air delay, and develops an algorithm for each type of claim based on the analysis result, It is preferable to easily generate and provide the proof-of-proof data.

4, a step (S400) of creating a claim letter according to a preferred embodiment of the present invention will be described in detail. FIG. 4 is a flowchart for describing in detail a step (S400) of creating a claim letter in a claim versus cost information processing method according to a preferred embodiment of the present invention.

The step S400 of creating a claim letter includes a step S410 of checking a claim event, a step S420 of sending out a claim notification letter, a step S430 of submitting detailed proofs, an approval judgment step S440, A notification step (S450), an appeal acceptance and a dispute preparation step (S460). At this time, the claim package is prepared and generated irrespective of the claim notification (S500). This will be described later with reference to FIG.

When it is confirmed that the claim event is generated in the step S410 of checking the claim event, the claim notification letter is sent (S420). However, if it is confirmed that the claim event is generated, the claim package is prepared (S500). The step of preparing a claim package (S500) is a step of preparing contents to be submitted in the detailed proof submission step (S430).

If the details of verification are submitted (S430), it is determined whether or not the approval has been made (S440). If the approval is not approved, the approval notification step S450 and the appeal acceptance and conflict preparation step S460, The claim is made through.

5, the following step S500 of preparing a claim package according to a preferred embodiment of the present invention will be described in detail. FIG. 5 is a flowchart for describing in detail a step S500 of preparing a claim package in a claim versus cost information processing method according to a preferred embodiment of the present invention.

Step S500 of preparing a claim package includes preparing a proof of project, arranging a project outline S510, reviewing an initial baseline S520, sorting a claim event list S530, A step S560 of reordering a claim event history (S550), a step S560 of creating a repetitive action group (Fragnet), a step S570 of selecting a delay analysis method (S570) Reviewing the progress and reviewing the delay analysis (S580), and creating a claim document (S590).

Step S500 of preparing the claim package when the claim type is for the air delay is the step of preparing the proof data for the air delay. In other words, it is a business procedure to prepare a claim document when filing an air delay claim from the contractor.

For example, if the air delay days are 10 days, the claims package will contain evidence such as why 10 days have passed, what parts of the schedule were originally changed, and 10 days have been delayed.

Claim documents are reviewed based on the degree of negligence between the contractors and the contents of the contract, and they are sometimes used as an anti-claim function to offset claims.

In order to use proved data as objective data to support the situation at the time of the proof data, it is desirable to manage the proof data as shown in the following table 5. Such evidence can be easily used in PMIS and construction project management.

If the claim package is generated (S500) and submitted with detailed proof (S430) and approved, the process proceeds to step S600 of managing the claim history.

The step S600 of managing a claim history according to a preferred embodiment of the present invention will be described in detail with reference to FIG. FIG. 6 is a flow chart for explaining step (S600) of managing a claim history in a claim versus cost information processing method according to a preferred embodiment of the present invention.

The step S600 of managing a claim history according to a preferred embodiment of the present invention includes a step S610 of creating a claim record list target, a step S620 of recording / storing a claim history, S630), and creating a status report (S640).

By managing the claim history in this way, it can be easily used as a reference when similar cases arise in the future, and the losses due to repeated claims can be significantly reduced.

Referring to FIG. 7, a main configuration of a claim-cost information processing system according to a preferred embodiment of the present invention will be described. FIG. 7 is a schematic diagram showing a main configuration of a claim-cost information processing system according to a preferred embodiment of the present invention.

The claim-cost information processing system 1000 according to a preferred embodiment of the present invention is based on the information processing method as described above and includes a claim management plan collection module 100, a claim identification monitoring module 200, A letter creation module 300, a claim package creation module 400, and a claim record management module 500.

The claim management plan collection module 100 is a module for performing a step S100 of establishing a claim management plan, which defines claim-related terms, identifies a claim type, establishes a claim promotion procedure, It is preferable to have a function of

The claim identification monitoring module 200 is a module for performing a step S200 of identifying and monitoring a claim, storing, supplementing, and collecting the created orderer, contractor, and other checklist form, and determining whether a claim event has occurred It is desirable to have a function capable of performing the above-described operation.

In a case where the claim-cost information processing system 1000 according to the preferred embodiment of the present invention is constituted by a software program operated on a machine such as a computer, the check list can be identified from the external information storage medium in a drag- To the monitoring module 200. At this time, a confirmation button is displayed on the computer display and the check list information is inputted to the claim identification monitoring module 200 when the user selects it.

In the case where an occurrence of a claim event is determined, and an event occurs in a monthly meeting, a progress report meeting, or when there is an anomaly when an empirical proof relative to a plan for a process is included, all the data are collected by the claim identification monitoring module 200 .

The claim letter writing module 300 is a module for performing a step S400 of creating a claim letter, and is a module for confirming a claim event, voicing a claim notice letter, submitting a detailed proof, .

In this case, the claim notice letter must be sent to the client, and it is decided to send it within 28 days from the moment of the claim event, or 14 days if the cause of the dispute is caused by the international contract. In order not to make a mistake by the practitioner, the claim letter writing module 300 preferably has an alarm notifying the date of the remaining time. Also, it is desirable that the letter letter creating module 300 stores letter forms in order to supplement the convenience and inexperience of the business person.

The claim package must be prepared even if you do not send a letter of claim notice. Here, it is desirable that the claims package be understood as evidence of air delay events. The claim package generation module 400 is a module for performing a step S500 of creating a claim package. The module includes a project summary, an initial baseline, a claim event list, a claim event, It is preferable to rearrange the event history, create a group of repeat activities, select a delay analysis method, review progress analysis and delay analysis, and create a claim document.

In addition, the claim package has to be submitted within 42 days after the claim event is confirmed, and the claim package generation module 400 is provided with an alarm notifying the date of the expiration date similarly to the claim letter creation module 300 desirable. In addition, when the claim-cost information processing system 1000 according to the preferred embodiment of the present invention is constituted by a software program operated on a machine such as a computer, the claim package is represented by a table of contents, So that the contents can be confirmed.

The claim record management module 500 is a module for performing the record management (S600) of managing the claim, and is a module for creating a claims record list object, recording / storing the claim record, managing the action history, .

As described above, according to the method of claim-cost information processing according to the present invention and the system therefor, claims management is performed through management of construction projects such as process and cost, and when a PMIS is utilized Integrated management of data generated during the process is possible.

1000: Claims vs. Cost Information Processing System
100: claims management plan collection module
200: Claim identification monitoring module
300: Claim Letter Creation Module
400: Claim Package Creation Module
500: Claim record management module

Claims (13)

(a) establishing a claims management plan;
(b) identifying and monitoring claims;
(c) determining whether a claim event has occurred;
(d) creating a claim letter;
(e) creating a claims package; And
(f) recording and managing a claim,
In the step (a), a claim promotion procedure and a countermeasure for claims are established,
The claim proceeding procedure is a procedure that includes the steps of securing the evidence data and making the claim document before and after the claim is filed,
The countermeasure for the claim is established by constructing a project management information system (PMIS) based on the construction project management system and the claim process procedure,
In the step (e), a repetitive activity group (Fragnet) is created in the claim package, a TIA (Time Impact Analysis) analysis method is selected to generate proof proof data,
In the case of carrying out the construction project management using the above PMIS, the initial planning data on the construction management items including the process and the cost and the data generated during the construction project are utilized as the data supporting the above proof data As a result,
How to process claim versus cost information.
The method according to claim 1,
The step (a)
(a1) defining a claim-related term;
(a2) classifying the type of claim based on the cause of the claim;
(a3) establishing a claim propulsion procedure; And
(a4) establishing a countermeasure for claims.
How to process claim versus cost information.
The method according to claim 1,
The step (b)
(b1) completing an order return checklist form;
(b2) completing a contractor checklist form;
(b3) completing the other return checklist form; And
(b4) supplementing or aggregating the claims management checklist.
How to process claim versus cost information.
The method according to claim 1,
Wherein said claim event includes matters that occur in a monthly meeting, a progress report meeting, or where an error occurs when a plan for a process is compared to an actual value.
How to process claim versus cost information.
The method according to claim 1,
The step (d)
(d1) confirming a claim event;
(d2) sending a claim notification letter;
(d3) submitting detailed proofs; And
(d4) an approval decision step.
How to process claim versus cost information.
The method according to claim 1,
The step (e)
(e1) organizing the project outline;
(e2) reviewing an initial baseline;
(e3) clearing the claim event list;
(e4) selecting a claim event;
(e5) rearranging the claim event history;
(e6) creating a repetitive activity group (Fragnet);
(e7) selecting a TIA delay analysis method;
(e8) reviewing the progress and delay analysis of the progress; And
(e9) creating a claim document.
How to process claim versus cost information.
The method according to claim 1,
The step (f)
(f1) creating a claim record list object;
(f2) recording or archiving a claim history;
(f3) managing the action history; And
(f4) generating a status report.
How to process claim versus cost information.
8. A system according to any one of claims 1 to 7,
Claims management plan collection module;
Claim identification monitoring module;
Claim Letter Creation Module;
A claim package generation module; And
Claim Claim Management Module,
In the claim management plan collection module, a claim promotion procedure and a countermeasure countermeasure are established,
The claim proceeding procedure is a procedure that includes the steps of securing the evidence data and making the claim document before and after the claim is filed,
The countermeasure for the claim is established by constructing a project management information system (PMIS) based on the construction project management system and the claim process procedure,
In the claim package creation module, a repetitive activity group (Fragnet) is created and a TIA (Time Impact Analysis) analysis method is selected to generate proof-of-claim data,
In the case of carrying out the construction project management using the above PMIS, the initial planning data on the construction management items including the process and the cost and the data generated during the construction project are utilized as the data supporting the above proof data As a result,
Claims cost information processing system.
9. The method of claim 8,
Wherein the claim management plan collection module has a function of defining a claim related term, determining a claim type, establishing a claim promotion procedure, and establishing a countermeasure for claims.
Claims cost information processing system.
9. The method of claim 8,
Wherein the claim identification monitoring module has a function of storing, supplementing, or collecting the created orderer, contractor, and other checklist forms, and determining whether a claim event has occurred.
Claims cost information processing system.
9. The method of claim 8,
Wherein the claim letter writing module is configured to check a claim event, speak a claim notice letter, submit a detailed proof, and determine whether or not to approve the claim.
Claims cost information processing system.
9. The method of claim 8,
The claim package generation module organizes the project outline, examines the initial baseline, organizes the claim event list, selects the claim event, rearranges the claim event history, creates the repetitive activity group, And to review the progress summary and the delay analysis, and to create a claim document.
Claims cost information processing system.
9. The method of claim 8,
Wherein the claim record management module is configured to create a claim record list target, record or archive a claim history, manage the action history, and generate a status report.
Claims cost information processing system.

Images